to disapprove alternate methods, even if they are more cost effective, if
the Contracting Officer determines that the proposed alternate method will
have an adverse environmental impact.
1.11
NOTIFICATION
The Contracting Officer will notify the Contractor in writing of any
observed noncompliance with Federal, State or local environmental laws or
regulations, permits, and other elements of the Contractor's Environmental
Protection plan. The Contractor shall, after receipt of such notice,
inform the Contracting Officer of the proposed corrective action and take
such action when approved by the Contracting Officer. The Contracting
Officer may issue an order stopping all or part of the work until
satisfactory corrective action has been taken. No time extensions shall be
granted or equitable adjustments allowed to the Contractor for any such
suspensions. This is in addition to any other actions the Contracting
Officer may take under the contract, or in accordance with the Federal
Acquisition Regulation or Federal Law.
1.12
HTRW PERIMETER AIR MONITORING
**************************************************************************
NOTE: The following paragraph pertains to HTRW
construction when the Designer has determined that
the need to protect Air Quality during HTRW remedial
action is necessary and appropriate. The paragraph
applies to contaminant emissions to the air from
HTRW remedial action construction area sources. The
Designer should coordinate the editing of
UFGS-01450A CHEMICAL DATA QUALITY CONTROL so that
the Chemistry Data Package, FSP and QAPP meet air
monitoring reporting and instrument/sample
collection and analysis needs.
An air pathway analysis needs to be conducted prior
to specifying the items in the subparagraphs below.
The Designer is referred to EP 1110-1-21 Air Pathway
Analysis (APA) for the Design of HTRW Remedial
Action Project. Design perimeter air monitoring
requirements (action levels for the contaminants of
concern, monitoring/sampling frequency) based on APA
results. Specify monitoring/sampling and analytical
requirements in section 01450A, CHEMICAL DATA
QUALITY CONTROL. Specify airborne contaminants of
concern, action levels, monitoring/sampling
locations below. See 40 CFR 300.430(e)(9) of the
National Contingency Plan.
**************************************************************************
For the protection of public health, the Contractor shall monitor and
control contaminant emissions to the air from HTRW remedial action area
sources to minimize short term risks that might be posed to the community
during implementation of the remedial alternative in accordance with the
following.
1.12.1
Perimeter Air Contaminant of Concern
[_____].
SECTION 01355A
Page 14
Previous Page
