requirements of SSPC QP 1 prior to contract award, and shall remain
certified while accomplishing any surface preparation or coating
application. The painting contractors and painting subcontractors must
remain so certified for the duration of the project. If a contractor's or
subcontractor's certification expires, the firm will not be allowed to
perform any work until the certification is reissued. Requests for
extension of time for any delay to the completion of the project due to an
inactive certification will not be considered and liquidated damages will
apply. Notify the Contracting Officer of any change in contractor
certification status.
][
**************************************************************************
NOTE: When using the contractor qualification
clause rather than the SSPC Certification
requirement, edit to require appropriate experience.
**************************************************************************
Submit the name, address, telephone number, FAX number, and e-mail address
of the contractor that will be performing all surface preparation and
coating application. Submit evidence that key personnel have successfully
performed surface preparation and application of coatings on [industrial
steel structures][___________] on a minimum of three separate projects
within the past three years. List information by individual and include
the following:
a.
Name of individual and proposed position for this work.
b.
Information about each previous assignment including:
Position or responsibility
Employer (if other than the Contractor)
Name of facility owner
Mailing address, telephone number, and telex number (if
non-US) of facility owner
Name of individual in facility owner's organization who can be
contacted as a reference
Location, size and description of structure
Dates work was carried out
Description of work carried out on structure
][1.4.3.6
Qualifications of Coating Manufacturer's Representative
**************************************************************************
NOTE: The inclusion of a manufacturers
representative in the pre-application meeting is
encouraged and is considered justified for large
projects. For smaller projects, the NACE inspector
can interface with the manufacturer for required
information and guidance.
**************************************************************************
Evidence of experience and training of the Coating Manufacturer's
Representative(s), including name, phone number and address, a statement
from the coating manufacturer certifying that the representative has
successfully completed all of the manufacturer's training for material
storage, mixing, application, and testing, has been directly involved in
evaluation and application of industrial coatings for not less than 10
steel structures within the last 5 years, and is not an employee of the
SECTION 09971
Page 14
Previous Page
