Remaining Durations, and Cost-to-Date shall be subject to the approval of
the Contracting Officer. As a minimum, the Contractor shall address the
following items on an activity by activity basis during each progress
meeting.
3.6.3.1
Start and Finish Dates
The Actual Start and Actual Finish dates for each activity currently
in-progress or completed .
3.6.3.2
Time Completion
The estimated Remaining Duration for each activity in-progress. Time-based
progress calculations shall be based on Remaining Duration for each
activity.
3.6.3.3
Cost Completion
The earnings for each activity started. Payment will be based on earnings
for each in-progress or completed activity. Payment for individual
activities will not be made for work that contains quality defects. A
portion of the overall project amount may be retained based on delays of
activities.
3.6.3.4
Logic Changes
All logic changes pertaining to NTP on change orders, change orders to be
incorporated into the schedule, contractor proposed changes in work
sequence, corrections to schedule logic for out-of-sequence progress, lag
durations, and other changes that have been made pursuant to contract
provisions shall be specifically identified and discussed.
3.6.3.5
Other Changes
Other changes required due to delays in completion of any activity or group
of activities include: 1) delays beyond the Contractor's control, such as
strikes and unusual weather. 2) delays encountered due to submittals,
Government Activities, deliveries or work stoppages which make re-planning
the work necessary. 3) Changes required to correct a schedule which does
not represent the actual or planned prosecution and progress of the work.
3.7
REQUESTS FOR TIME EXTENSIONS
In the event the Contractor requests an extension of the contract
completion date, or any interim milestone date, the Contractor shall
furnish the following for a determination as to whether or not the
Contractor is entitled to an extension of time under the provisions of the
contract: justification, project schedule data, and supporting evidence as
the Contracting Officer may deem necessary. Submission of proof of delay,
based on revised activity logic, duration, and costs (updated to the
specific date that the delay occurred) is obligatory to any approvals.
3.7.1
Justification of Delay
The project schedule shall clearly display that the Contractor has used, in
full, all the float time available for the work involved with this request.
The Contracting Officer's determination as to the number of allowable days
of contract extension shall be based upon the project schedule updates in
effect for the time period in question, and other factual information.
SECTION 01320A
Page 13
Previous Page
