for acceptance a [design and ]construction schedule in the form of a
[progress chart] [Critical Path Method (CPM), Network Schedule] in
accordance with the terms in Contract Clause "FAR 52.236-15, Schedules for
Construction Contracts," except as modified in this contract.
[1.3
EQUIPMENT DELIVERY SCHEDULE
**************************************************************************
NOTE: Delete this requirement if a Network Analysis
Schedule will be required on this project.
**************************************************************************
1.3.1
Initial Schedule
**************************************************************************
NOTE: Specify less time for short term projects.
Specify more time for projects having extensive
equipment requirements.
**************************************************************************
Within [30] [_____] calendar days after acceptance of the proposed [design
and ]construction schedule, submit for Contracting Officer acceptance a
schedule showing procurement plans for materials and equipment. Submit in
the format and content as prescribed by the Contracting Officer, and
include as a minimum the following information:
a.
Description.
b.
Date of the purchase order.
c.
Promised shipping date.
d.
Name of the manufacturer or supplier.
e.
Date delivery is expected.
f.
Date the material or equipment is required, according to the
current construction schedule.
]
[1.4
NETWORK ANALYSIS SCHEDULE (NAS)
**************************************************************************
NOTE: Delete this requirement if an Equipment
Delivery Schedule will be required on this project.
Determine the minimum number of activities based on
the complexity of the project, but should be no more
than one activity for every ,000 of contract value.
**************************************************************************
[The Contractor shall use the critical path method (CPM) to schedule and
control construction activities. The Network shall have a minimum of
[_____] construction activities. The scheduling software that will be
utilized by the Government on this project is [SureTrak by Primavera
Systems, Inc.][Primavera Project Planner (P3) by Primavera Systems, Inc.].
Notwithstanding any other provision in the contract, schedules submitted
for this project must be prepared using either Primavera P3 or Primavera
SureTrak (files saved in Concentric P3 format). Submission of data from
another software system where data conversion techniques or software is
used to import into Primavera's scheduling software is not acceptable and
SECTION 01320N
Page 4
Previous Page
